General terms and conditions of sale
The purpose of these General Terms and Conditions of Sale is to set forth the relation ships between CLESTRA, hereinafter referred to as “CLESTRA”, and the CUSTOMER, hereinafter referred to as the “CUSTOMER”.
Unless otherwise strictly specified by CLESTRA, all orders that it delivers and all contracts that it concludes are, without exception, subject to the general terms and conditions of sale, with any other documents such as brochures and catalogues issued by CLESTRA being only of an indicative character and having no contractual effect.
These provisions may be supplemented by terms and conditions specific to some products and, if the need arises, by Particular Terms and Conditions, which will in any event constitute an integral part hereof.
Terms of purchase specific to the CUSTOMER, specifications of architectural or engineering consultants or any other printed or handwritten provisions that appear in any letters or documents that CLESTRA has not formally agreed to in writing prior to the conclusion of the contract, shall not be invoked by the CUSTOMER.
The same shall apply to any commitment made by one of the representatives, agents or any other delegate of CLESTRA, to which CLESTRA has not agreed beforehand.
The CUSTOMER commits to transmit to CLESTRA any information necessary for the establishment of the terms and conditions of an offer.
CLESTRA shall not be liable for any constraint that is not reported by the CUSTOMER.
CLESTRA’s offer contains a period of time within which it remains valid for acceptance; unless otherwise expressly stipulated, the offer is valid for 30 days from the date of its transmission.
Thereafter, CLESTRA shall be released from any obligation, unless it expressly agrees in writing to renewal of the offer subject to updating of its term and to any technical or economic readjustment that it deems necessary.
The CUSTOMER’s acceptance of the offer is deemed to be adherence to the General Terms and Conditions. After the CUSTOMER’s acceptance of the offer, such offer cannot be terminated or rescinded by the CUSTOMER without determination, by amicable or judicial means, of an indemnification, particularly for the costs incurred by CLESTRA in consequence thereof.
If the customer decides, whatever the reason, to cancel his order CLESTRA shall be entitled to invoice the customer for a minimum of 10% of the total amount of such order if the cancellation is notified to it at least 30 days before the beginning of the work, and 20% if such cancellation is notified less than 30 days before the beginning of the work, in order for CLESTRA to be compensated for the expenses incurred by the preparation of the offer, including but not limited to the costing, the studies, the plans, the travel expenses.
Only written and accepted offers bind CLESTRA to its CUSTOMERS, within the limit of the following reservations:
- Weights and linear and square metres specified in estimates and contracts are purely for indicative purposes and are not contractual in effect. In no event shall they be subject to claims from the CUSTOMER in case they are modified.
- When estimates include the specification of certain profiles or samples of raw materials, such materials may, at the time of the execution, be replaced by others of a quality that is equivalent to, or complies with, the same specifications, or because the replacements are considered to be more adapted to the purpose of the offer.
It may happen that CLESTRA’s written confirmation does not precisely adopt the terms of the CUSTOMER’s offer or order. In such case, if the CUSTOMER does not submit any comments in writing within eight days of its receipt, the confirmation shall be deemed to be fully accepted and shall serve as proof in the event that a dispute arises related to any contrary prior stipulation.
Additional supplies shall be subject to amendments specifying the requirements for their execution.
3. CONTENT OF SUPPLIES AND WORK
The order confirmed by CLESTRA precisely and restrictively determines the nature and scope of the supplies and work to be performed. Fixed prices are always to be understood to apply in respect to the specifications and quantities appearing in the order. Any change in the terms and conditions specified in the order, particularly in the specifications and quantities, and any additional work must be subject to a written agreement regarding its content and its definition as well as its price.
The contract includes:
- CLESTRA’s offer accepted by the CUSTOMER
- If the need arises, additional specific terms and conditions and/or particular terms and conditions
- These General Terms and Conditions of Sale accepted and signed by the CUSTOMER
- The down payment upon placement of the order.
The various documents that comprise the contract must be considered to be mutually explanatory; however, in the case of ambiguities or divergences, they shall prevail in the following order of priority: 22.214.171.124
CLESTRA reserves the right to totally or partially subcontract its performance under the contract, particularly in respect to performance of the assembly.
In that event, CLESTRA’s sole obligation is to guarantee the CUSTOMER that the subcontractor’s performance is in compliance with the contract and its own standards, with a written definition of its legal relation ships with said subcontractor.
6. INTELLECTUAL PROPERTY
Any studies, projects, plans or documents provided or transmitted by CLESTRA are and remain the latter’s exclusive property. The CUSTOMER commits to promptly return them at its expense upon CLESTRA’s simple request.
They shall not be used, provided to others, reproduced or executed, even partially, by any means whatsoever, without CLESTRA’s prior written authorization.
The studies and documents are provided gratis if they are followed by the order to which they relate. Otherwise, CLESTRA reserves the right to claim reimbursement for the study and travel expenses in curred for the establishment of said studies and documents, as well as for the return thereof.
7. ON-SITE ASSEMBLY AND MISCELLANEOUS WORK
The CUSTOMER commits to have a clean, easily accessible worksite ready for assembly, which is made available to CLESTRA under the conditions and within the times specified in the Particular Terms and Conditions of the contract, particularly with lifting equipment, dry and cleared unloading and storage areas to be provided gratis. Under the agreed terms, the CUSTOMER shall be responsible for having the worksite in conformity with the availability and in the conditions specified by CLESTRA, and in no event shall the latter be subject to com plaints or claims in the event of delay due to non-compliance with this provision.
8. PRICES AND TIME LIMITS
Unless another deadline for acceptance is specified in the offer, the proposal related to prices (even with a revision formula) and delivery time are only valid for 30 days pursuant to the above article 2.
Any newly-imposed, modified or eliminated taxes that might affect the sale price, especially a change in the VAT, which occurs between the time of the offer and the time of the invoice shall be fully passed on and invoiced to the CUSTOMER.
Also, a variation in any other ancillary costs related to the invoice shall result in a corresponding variation in the agreed price.
When contracts are renewed, their basic price shall not automatically be determined on the basis of the prices of previous contracts by applying the parametric updating formula that the latter might have contained.
9. PRICE REVISION
Revision consists of taking into account, in order to calculate the invoice price, the economic variations that occurred between the issue of the offer and the date of revision.
10. TERMS OF PAYMENT
Payments are made in ILLKIRCH GRAFFENSTADEN, net and without discount, in EUROS, unless otherwise stipulated, and are due under the terms specified in the offers and quotations, order confirmations or invoices.
All costs related to any sale on credit or against securities, guarantees, pledges or any other similar types of sale shall be covered exclusively by the CUSTOMER.
Payment is deemed to be made upon the effective collection of the price, without the remittance of a draft or any other item creating an obligation to pay constituting payment.
The dates of payment cannot be delayed or changed for any reason whatsoever, even in the event of disputes.
Non-acceptance or non-return of an instrument of payment, suspension of payment for any reason, unauthorized offsetting and refusal of receipt are deemed to be defaults of payment. The same applies in the event of a sale, pledging or contribution of the CUSTOMER’s business or equipment.
In no event shall the payments be subject to any offsetting without CLESTRA’s prior written agreement.
In the event of a defaulted or late payment, all of the sums owed by the CUSTOMER in any regard whatsoever become immediately due and payable without the need for a notice.
Without prejudice to the foregoing, any sum unpaid on its agreed due date automatically results, commencing on said date, in the application of penalties at the interest rate applied by the BCE increased by 7 points, without prejudice to the application of a rate increase specified by law in the event of a judicial order.
In addition, the costs and fees incurred for legal collection of outstanding sums shall always be covered by the CUSTOMER.
11. RESCISSION CLAUSE
Without prejudice to the provisions of article 10, the contract shall automatically be terminated or rescinded at the discretion of CLESTRA if the CUSTOMER fails to meet any of its obligations, such as a defaulted or late payment on the agreed due date of any sums owed here under, 8 days after a notice there to demanding performance has remained fruitless, without prejudice to CLESTRA’s right to claim all damages and interest.
It is particularly agreed that any instalment already paid by the CUSTOMER shall be retained by CLESTRA as damages and interest.
If one of the events that are contractually considered as a case of force majeure, described hereinafter, occurs in such a way as to delay or prevent performance of the contract or to make such performance impossible due to its exorbitant cost, the contract shall be suspended or even rescinded at CLESTRA’s discretion, upon notification by registered letter with an acknowledgement of receipt to the CUSTOMER, without any indemnification.
The same applies in the event of fires, strikes, lockouts, floods, mechanical break downs in the premises of CLESTRA or its suppliers or subcontractors, wars, riots, requisitions, technical closings, equipment failures and loss of important parts in the process of manufacturing, all causes leading to total or partial unemployment, delay in transport, impossibility of obtaining supplies under normal conditions, and any circumstance that is beyond CLESTRA’s control that prevents normal performance of this contract.
12. DELIVERY / TIME LIMITS
CLESTRA must comply with the times appearing in its offers subject to the following conditions:
- Fulfilment by the CUSTOMER of its own contractual obligations, particularly compliance with the terms and conditions, availability of the worksite, payment, transmission of all information and execution of all items of work that are necessary to prepare the worksite for performance of the contract.
- Non-occurrence of one of the events of force majeure or an event as described above in article 11. Compliance by the CUSTOMER with the date of shipment and the work necessary to assemble the equipment on the site. Modification of work, unforeseen work and, generally, any tardiness in delivery or performance of the contract which is not directly due to CLESTRA’s acts or omissions. All costs and risks related to non-delivered equipment within the specified times for reasons that are not imputable on CLESTRA are to be covered exclusively by the CUSTOMER.
Any late delivery or performance of the contract for reasons that are not imputable to CLESTRA shall not, by any means, result in rescission of the contract or in the payment of any penalties or damages and interests.
In no event shall CLESTRA be held liable for any forthcoming constraint which had not been reported by the CUSTOMER, for instance:
- Difficulty of access to, or emplacement of, the installation
- Other equipment or supplies that may impair contract performance
- and, generally, any other construction work prior to that of CLESTRA.
Any late delivery or performance of the contract for reasons that are not imputable to CLESTRA automatically defers the date of work acceptance by a period equal to the period of such delay.
Any delay due to the acts or omissions of third parties that creates further difficulties in realization of the contract shall be invoiced to the CUSTOMER with documentation thereof.
A late delivery or performance provides the right to claim damages and interest only if, due to CLESTRA’s acts or commissions, it constitutes an actual injury observed by both parties and if the contract expressly specified such possibility, with a reciprocal premium payable in the event of completion of work prior to the contractual deadlines.
If such a penalty is expressly stipulated, it shall not in any circumstance exceed 5% of the factory price net of taxes of the equipment which was delivered belatedly.
13. PACKAGING AND TRANSPORT
Unless otherwise specified in writing by CLESTRA, the prices include the manufacturing, transport, unloading, on- site installation and assembly of the equipment.
The CUSTOMER must take all steps necessary to have the equipment that is not assembled on its request stored in conditions upon its arrival that are required for its proper preservation, and is responsible for the costs of such storage.
The supplies, even shipped with carriage and packaging paid, always travel at the CUSTOMER’s risk and peril; in the event of late delivery, defects or missing items, the CUSTOMER shall take action against the carriers, or submit reservations to them in order to exercise such an action.
The packaging is not recovered by CLESTRA.
14. WARRANTY AND LIABILITY
The CUSTOMER is provided with the legal warranties specified in article 1792 and those that follow and article 2270 of the Civil Code (total completion warranty, proper operation warranty, ten -year warranty).
In order to invoke the coverage of these warranties, the CUSTOMER must have met the contractual specified terms of payment, must have advised CLESTRA, without delay and in writing, of the defects that it observed in the equipment, and must provide all proofs regarding the reality thereof. The CUSTOMER must also facilitate the procedure for the establishment and correction of these defects.
The CUSTOMER may invoke warranties regarding manufacturing results, particularly in matters of acoustics and fireproofing, only if the parties establish in writing their agreement to these warranties.
In no circumstance shall the indemnification that might be provided in that regard exceed 5% of the factory value net of taxes of the incriminated equipment.
The above provisions constitute the only liability incurred by CLESTRA vis-à-vis the CUSTOMER to the exclusion of indemnification for any other injuries or costs resulting directly or indirectly from CLESTRA’s defective supplies or services, unless CLESTRA committed an act or omission of gross negligence. If the CUSTOMER requires CLESTRA to use materials of a specific quality, origin or type, or of a particular execution design or process, CLESTRA shall not in any circumstance be held liable for any defects that may result therefrom.
15. RESERVATION OF OWNERSHIP
- As an essential condition, it is expressly stipulated that the delivered goods remain CLESTRA’s property until full payment of the price, costs and ancillary items. However, the CUSTOMER bears the risks for those goods as soon as they leave CLESTRA’s plants.
- CLESTRA may exercise the rights that it holds under this provision on all of its goods in the CUSTOMER’s possession, if the latter are, by express agreement, deemed to be unpaid.
- In the event that CLESTRA claims the delivered goods pursuant to this provision, the costs there of, particularly those of return, shall be covered by the CUSTOMER.
- In the event of a multiplicity of claims, the reserved ownership guarantees all present or future claims on the CUSTOMER.
- In the event of a claim, the insurance indemnification shall automatically be subrogated to the goods which remain under CLESTRA’s ownership.
- The CUSTOMER must maintain the goods in an impeccable state and must insure them for the account of CLESTRA.
- Any modification, transformation or alteration of the goods is prohibited. In the event of the CUSTOMER’s non-compliance with this prohibition, the CUSTOMER as of now transfers to CLESTRA the ownership of the transformed goods in order to guarantee CLESTRA’s rights.
- The CUSTOMER must immediately inform CLESTRA in the event of judicial administration or liquidation, as well as any attachment or other measure affecting the goods. The CUSTOMER is prohibited from pledging the goods as security for debt or otherwise encumbering them through any transaction that mig ht infringe CLESTRA’s proprietary right.
- The CUSTOMER is prohibited from selling the goods prior to full payment of the price thereof without CLESTRA’s prior agreement. Should the CUSTOMER fail to comply with this prohibition, the CUSTOMER as of now declares assignment of the claim arising from the resale to a sub-purchaser. The CUSTOMER cannot receive the price owed by the sub-purchaser up to the amount remaining due to CLESTRA, and commits to inform the sub-purchaser of the assignment of claims of which CLESTRA is the beneficiary.
After an attempt to reach an agreement by amicable means has failed, it is expressly agreed that any dispute related to contracts, orders and these presents shall be submitted exclusively to the competent Courts sitting in the area of CLESTRA’s registered office, even in the presence of a multiplicity of defendants or actions to enforce guarantees, unless CLESTRA prefers to refer the matter to any other competent Court.
Neither drafts nor acceptance of payment by cheques or any other bills in a city other than the location of the registered office constitute a substitution of, or an exception to, this attribution of jurisdiction.
GENERAL TERMS OF SALE – POD RANGE - DECEMBER 2017
1. GENERAL POINTS
The purpose of these General Terms of Sale (hereafter called the GTS) is to govern the dealings between CLESTRA HAUSERMAN, a public limited company with capital of €4,741,000, registered office 1 route du Docteur Albert Schweitzer 67411 ILLKIRCH, FRANCE registered on the Strasbourg Trade and Companies Register under the number 798 005 674, hereafter called "CLESTRA", and its CUSTOMERS for the sale of the products of POD range (IRYS and FIZZBOX) hereafter called the “Product(s)”.
2. POD RANGE
The Products of POD range are furniture units comprising a ceiling, partitions, an air renewal system and integrated lights which creates an autonomous and independent free-standing space within the structure of the building.
The Products are intended to be fitted into office spaces, meeting rooms, reception areas or relaxation areas. They have not been designed for industrial, sanitary or security installations. CLESTRA disclaims all liability for non-compliance with the Products' intended use.
3. FORMATION OF THE CONTRACT
The CONTRACT is formed by CLESTRA's technical and sales offer negotiated with the CUSTOMER, also called Special Conditions (SP) and these GST, and excludes any purchase or clause or General Terms of Purchase specific to the Customer which may appear in any document or correspondence irrespective of the medium. If there is a conflict between the SP and the GST, the provisions of the SP will take precedence over the GST. Unless otherwise specified, the version of the technical and sales offer will remain valid for 30 days from its issuance date. Once the offer has been accepted and the CONTRACT formed, the contract cannot be the subject of any unilateral modification, termination or rescission by the CUSTOMER
The CUSTOMER agrees to the documents and information being transmitted electronically including during the pre-contractual phase. These exchanges will be considered to be contractual from the moment that an acknowledgement of receipt is given by email by the contact person designated in the CONTRACT.
4. INFORMATION - ADVICE - GOOD FAITH
The CUSTOMER states that it has communicated all the information required for establishing the CONTRACT to CLESTRA, and states that it received all necessary advice and all information required for its consent from CLESTRA prior to the formation of the CONTRACT. CLESTRA and the CUSTOMER agree to deal with each other fairly and to act honestly at all times.
The CUSTOMER is informed and agrees that CLESTRA can entrust all or part of the performance of the CONTRACT to third parties.
5. INTELLECTUAL PROPERTY
All the intellectual property rights attached to the Products as well as all the studies, plans, drawings and documents of all kinds handed by CLESTRA to the CUSTOMER are and remain its property. The CUSTOMER shall return the above-mentioned documents at its costs immediately, if requested by CLESTRA. They cannot be used, disclosed, reproduced or executed in any way whatsoever, even partially, without CLESTRA's prior approval.
6. REQUIREMENTS FOR THE INSTALLATION
The Products must be fitted in an enclosed, covered, dry area with an ambient temperature of between 12° and 30°, which is clean, accessible, fitted with suitable electricity access and a minimum under ceiling height suitable with regard to the project, a level floor, in its finished condition and with a sufficient surface area for the Products installation and in general in compliance with the conditions of DTU 35.1.
7. TRANSPORT AND INSTALLATION
Unless otherwise specified in the SP, (and apart from sales by distributors) CLESTRA's team will be responsible for transporting, delivering and installing the Products. The electricity connection to the Products inside the building is not included in CLESTRA's installation service.
The CUSTOMER must inform CLESTRA as soon as it is aware of any factor which could have an impact on the installation such as problems of access, the presence of other equipment or supplies on the work site which could affect the performance of the CONTRACT, performing works in occupied areas etc.
The CUSTOMER is solely liable for making the work site available in conformity with the conditions of article 6 and no claims can be made against CLESTRA for a delay attributable to the non respect of this obligation.
The installation is considered to be completed when the acceptance report has been signed, or failing this, within 30 days of the date of delivery on the delivery slip, part from a written dispute by the CUSTOMER. All visible defects and those attached to the installation are considered to have been removed on the completion date.
The 1) Price of the Products, 2) the price of preparation and installation 3) the price of the transport are fixed separately in the SP. If there is no specification in the SP, the price must be considered to be exclusive of preparation, installation and transport. Prices are net of tax and customs costs.
9. PRICE REVIEW
A price review can be performed if CLESTRA's intervention date is postponed more than 3 months compared to the provisions in the CONTRACT.
In addition if an unforeseeable change in the circumstances when the CONTRACT was concluded makes the performance of the CONTRACT excessively expensive, CLESTRA can renegotiate the CONTRACT or demand its termination.
10. TERMS OF PAYMENT
The terms of payment are set out in the SP. Failing this, the whole of the price is payable on order.
Payment is made when the price is encashed. The payment terms cannot be delayed or modified for any reason whatsoever even for litigious reasons. Payments cannot be offset by the CUSTOMER in any way without CLESTRA's prior written agreement.
In the event of a delay or default in payment, all sums owed by the CUSTOMER in anyway will fall due without any formal demand being required. Without prejudice to the above, penalties at the ECB's interest rate increased by 10 points, will automatically accrue on any sum which is unpaid on the agreed due date together with a 40 Euro indemnity for collection costs. This indemnity will be automatically owed for each unpaid invoice from the first day of late payment. This lump sum indemnity is not exclusive of any other costs which CLESTRA could owe for collecting its invoices. The CUSTOMER will always owe the costs and fees incurred to recover sums owed.
11. TERMINATION CLAUSE
Without prejudice to the other provisions of article 10 the CONTRACT will be automatically terminated or rescinded at CLESTRA's discretion if the CUSTOMER fails to perform any of its crucial obligations fifteen days after formal notice which has been ineffective. It is now agreed that CLESTRA will keep all the sums already paid by the CUSTOMER as damages, and it is agreed that these sums will only constitute a minimum contractual indemnification. The CUSTOMER shall indemnify the whole of the loss suffered by CLESTRA for this termination or rescission.
If an event which is contractually compared to a case of force majeure in article 12 occurs which is liable to delay, obstruct or make the performance the CONTRACT excessively expensive, the CONTRACT will be suspended or terminated without indemnity by CLESTRA by recorded delivery letter with acknowledgement of receipt to sent to the CUSTOMER.
Delivery deadlines only run from the signature of the contract and if necessary the payment of the price or the down payment by the CUSTOMER. The installation deadlines stated in the SP only run from the completion of preparation of the work site.
Unless otherwise stated in the SP, the deadlines for delivery, preparation for installation, and installation are given for guidance only. If the SP expressly stipulate a firm deadline for delivery, preparation for installation and/or installation, CLESTRA must unreservedly comply with these deadlines, providing :
- the CUSTOMER performs all its own contractual obligations in full,
- there is no occurrence of a case of force majeure such as: epidemic, state of war, requisition, fire, flooding, tooling accident, strike, transport or information network disruptions, shortage of raw materials or energy sources and in general any other cause resulting in a total or partial stoppage of CLESTRA's business activity or the activity of its suppliers, subcontractors or carriers,
- there is no modification to the CONTRACT even a minor modification (product, quantity, deadline, condition, etc).
Any delay in delivery or in performing the CONTRACT for any reason which is totally or partially attributable to the CUSTOMER or to a third party will automatically result in the delivery date or the date of acceptance of the works being postponed for at least an equal duration.
A delay in delivery or performance can only result in a penalty or damages if, being exclusively attributable to CLESTRA, it constituted a real loss which has been jointly established, and if the SP expressly provided for this eventuality with the reciprocity of a premium in the event of an advance. If such a penalty has been expressly stipulated, it can never exceed 5% of the price of the Products exclusive of VAT.
13. WARRANTY AND LIABILITY
CLESTRA warrants the Products against any nonconformity or hidden defect which is found in the design or manufacture within two years of its delivery date.
In order to be able to invoke this warranty, the CUSTOMER must have 1) paid for the Products in full 2) informed CLESTRA immediately of the fault, in writing 3) provided proof of the existence of the defect and its existence at the time of sale and 4) specified the intended purpose and use of the Products.
The warranty only covers the repayment, repair or replacement by CLESTRA at its discretion and at its costs of all or part of the Product acknowledged to be defective. The implementation of the warranty will not prolong it.
The warranty is excluded :
- for damage or accident caused by transport, an installation defect not indicated when the installation is completed or caused by the negligent surveillance or maintenance of the CUSTOMER or a third-party,
- if the Product is used in abnormal conditions or which do not conform to its intended purpose,
- if the CUSTOMER has modified, moved or repaired the Product or had the Product modified, moved or repaired by a third-party,
- for damage which is caused by an act of God, a force majeure or a negligent act by the CUSTOMER or a third-party.
The warranty does not cover the replacement or repair of parts of the Product subject to the normal wear and tear.
The CUSTOMER is informed that the glazing in the partitions in the Products may be made from toughened non-HST treated glass. The glass may therefore include nickel sulphide inclusions (NIS) which can cause it to break. These inherent and inevitable inclusions in the glass are not faults or hidden defects which would call the warranty and/or CLESTRA's warranty into play. The CUSTOMER can opt for HST treated glass on request and specific offer. HST heat treatment reduces the risk of spontaneous breakage without removing it altogether.
CLESTRA's liability is strictly limited to the obligations stipulated in the CONTRACT and in any event, to the direct and foreseeable physical damage which is limited to the amount of the CONTRACT exclusive of VAT. CLESTRA will not be liable for any other indemnity, apart from wilful negligence and for the repair of physical damage. The CUSTOMER can never hold CLESTRA liable to indemnify consequential and/or immaterial damage, whether consecutive or not, such as lost earnings, operating losses or any commercial loss.
14. RETENTION OF TITLE
It is an essential condition that CLESTRA retains the ownership title in the Products until full payment of the price, costs and incidental expenses. However, the risks in the Products are transferred to the CUSTOMER as soon as the Products leave CLESTRA's factories.
If CLESTRA demands the return of the Products under this clause, the related costs, notably the costs of dismantling and return will be paid by the CUSTOMER
The CUSTOMER must keep the Products in an impeccable condition and insure it on CLESTRA's behalf until it is paid for in full. In the event of a claim the insurance indemnity will be automatically subrogated to the property which CLESTRA has continued to own.
The CUSTOMER must immediately inform CLESTRA of any administration proceedings, winding up by the court, sequestration or any other measure affecting the property. It is prohibited to constitute a security over the property and perform any operation which is likely to prejudice CLESTRA's ownership title right. It is prohibited to sell the Products before complete payment of the price without CLESTRA's prior agreement. If the CUSTOMER infringes this ban, CUSTOMER now states that it assigns the receivable created by the resale to a sub-purchaser to CLESTRA. The CUSTOMER cannot receive the price owed by the sub purchaser, up to the amount of the outstanding sums to CLESTRA and it must inform the sub-purchaser of the assignment of receivables to CLESTRA.
15. GOVERNING LAW - JURISDICTION
The CONTRACT is subject French law. Any dispute which cannot be settled amicably will be brought before the competent courts for the place of CLESTRA's registered office even if there are multiple defendants or third party proceedings.
Neither bills or the acceptance of payment of cheques or any paper whatsoever in another city other than the place where CLESTRA's registered office is located can be a novation or exception to this jurisdiction clause.